NTPC LTD. vs M/S. DECONAR SERVICES PVT. LTD. — C.A. No. 6483/2014

Case under Section XIV-A. Status: Disposed.

Disposed

CNR: SCIN010212772010

Filing Date

12-Jul-2010

Registration No

C.A. No. 6483/2014

Diary Number

21277/2010

Order Date

04-Mar-2021

Document Type

Judgement - of Main Case

Neutral Citation

2021 INSC 148

Disposal Type

Dismissed

Last updated 06-Jul-2026

Acts & Sections

Section XIV-A

Petitioner(s)

  1. 1.NTPC LTD.

    Adv. PUNEET TANEJA (Dead / Retired / Elevated)

Respondent(s)

  1. 1.M/S. DECONAR SERVICES PVT. LTD.

    Adv. S. RAJAPPA[Caveat]

Case History

  1. Case disposedDisposed

  2. 04-Mar-2021

    Judgement - of Main CaseView PDF

  3. 04-Mar-2021

    ROP - of Main CaseView PDF

  4. 04-Mar-2021

    Fixed Date by Court

    Hon'ble Mr. Justice N.V. Ramana, Hon'ble Mr. Justice Surya Kant and Hon'ble Mr. Justice Aniruddha Bose

  5. 24-Feb-2021

    ROP - of Main CaseView PDF

  6. 24-Feb-2021

    Fixed Date by Court

    Hon'ble Mr. Justice N.V. Ramana, Hon'ble Mr. Justice Surya Kant and Hon'ble Mr. Justice Aniruddha Bose

  7. 18-Feb-2021

    ROP - of Main CaseView PDF

  8. 18-Feb-2021

    Next Week / Week Commencing / C.O.Week

    Hon'ble Mr. Justice N.V. Ramana and Hon'ble Mr. Justice Aniruddha Bose

  9. 10-Feb-2021

    ROP - of Main CaseView PDF

  10. 10-Feb-2021

    First hearing

    Initial hearing scheduled

  11. 14-May-2015

    ROP - of Main CaseView PDF

  12. 14-May-2015

    Office Report - of Main CaseView PDF

  13. 14-May-2015

    ROP - of Main CaseView PDF

  14. 14-Jul-2014

    ROP - of Main CaseView PDF

  15. 17-Feb-2014

    ROP - of Main CaseView PDF

  16. 30-Sep-2013

    ROP - of Main CaseView PDF

  17. 19-Jul-2013

    ROP - of Main CaseView PDF

  18. 17-Feb-2012

    ROP - of Main CaseView PDF

  19. 18-Feb-2011

    ROP - of Main CaseView PDF

  20. 10-Jan-2011

    ROP - of Main CaseView PDF

  21. 25-Nov-2010

    ROP - of Main CaseView PDF

  22. 06-Aug-2010

    ROP - of Main CaseView PDF

  23. 12-Jul-2010

    Case filed

    Registration No. C.A. No. 6483/2014

  24. [ 2021 INSC 148 ]

    Judgement - of Main CaseView PDF

View Full Judgment
casestatus.in Summary

Case Summary: NTPC Ltd. v. M/s Deconar Services Pvt. Ltd. The Supreme Court dismissed NTPC's appeals challenging an arbitrator's awards totaling approximately Rs. 48 lakhs to contractor Deconar for construction delays. The Court upheld the arbitrator's interpretation that the 16% rebate was conditional on simultaneous execution of both projects, and that price escalation applied beyond the scheduled period since NTPC delayed site handover—holding courts cannot reappraise arbitral awards when arbitrators take reasonable, possible views supported by evidence. This case analysis is maintained by casestatus.in based on publicly available court records.

Explore other courts

High Courts District Courts
Search Another Case