PUNE CANTONMENT BOARD vs M.P.J. BUILDERS — C.A. No. 9390/1996

Case under Section III. Status: Disposed.

Disposed

CNR: SCIN010015851995

Filing Date

28-Jan-1995

Registration No

C.A. No. 9390/1996

Diary Number

1585/1995

Order Date

09-Aug-1996

Document Type

Judgment - of Main Case

Disposal Type

Dismissed

Last updated 30-May-2026

Acts & Sections

Section III

Petitioner(s)

  1. 1.PUNE CANTONMENT BOARD

    Adv. IRSHAD AHMAD

Respondent(s)

  1. 1.M.P.J. BUILDERS

Case History

  1. Case disposedDisposed

  2. 09-Aug-1996

    Judgment - of Main CaseView PDF

  3. 28-Jan-1995

    Case filed

    Registration No. C.A. No. 9390/1996

View Full Judgment
casestatus.in Summary

Summary of Pune Cantonment Board v. M.P.J. Builders (1996) The Supreme Court set aside the High Court's order and upheld the GOC-in-Chief's cancellation of a time extension for building construction. The builders' original sanction (1981) expired in 1983, but no construction had begun by 1985 despite intervening building bye-law restrictions. The Court found the Cantonment Executive Officer's extension order (1986) lacked jurisdiction and reasoning, violated statutory limits on extensions, and arbitrarily disregarded changed circumstances. However, the Court permitted the builders to retain and complete the partially constructed structure. This case analysis is maintained by casestatus.in based on publicly available court records.

Explore other courts

High Courts District Courts
Search Another Case