COURT ON ITS OWN MOTION(Not Applicable) vs NHAI AND ANOTHER(Not Applicable) Advocate - Shreya Chauhan, ,Rajesh Kashyap,AG — CWPIL/86/2025

Case under Constitution of India Section 226. Next hearing: 30th June 2026.

Next hearing 30-Jun-2026

CNR: HPHC010554552025

Filing Number

CWPIL/46965/2025

Filing Date

05-Sep-2025

Registration No

CWPIL/86/2025

Registration Date

05-Sep-2025

Judge

Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Bipin Chander Negi

Coram

Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Bipin Chander Negi

Bench Type

Single

Judicial Branch

Civil Section

Last updated 02-Jun-2026

Acts & Sections

Constitution of India Section 226

Petitioner(s)

  1. 1.COURT ON ITS OWN MOTION(Not Applicable)

    Adv. NEMO

Respondent(s)

  1. 1.NHAI AND ANOTHER(Not Applicable) Advocate - Shreya Chauhan, ,Rajesh Kashyap,AG

  2. 2.The Secretary(Not Applicable)

Case History

  1. 30-Jun-2026

    Next hearingPending

  2. 30-Jun-2026

    Admission After Notice

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Bipin Chander Negi

  3. 19-May-2026

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia,hon'ble Mr. Justice Bipin Chander NegiView PDF

    Summary: CWPIL No. 86/2025 The court adjourned the case regarding a Rs. 469-crore highway 4-laning project (Majrihatta to Nalagarh Chowk). The court expressed concern over NHAI's administrative lapses causing 3-year delays in land acquisition, leading contractor Patel Infrastructure Limited to withdraw via settlement agreement on 09.10.2025. NHAI was directed to file comprehensive affidavits detailing payment amounts, foreclosure justification, and maintenance contract progress. Matter listed for 30.06.2026. This case analysis is maintained by casestatus.in based on publicly available court records.

  4. 19-May-2026

    Admission After Notice

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Bipin Chander Negi

  5. 05-May-2026

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia,hon'ble Mr. Justice Bipin Chander NegiView PDF

  6. 05-May-2026

    Admission After Notice

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Bipin Chander Negi

  7. 17-Mar-2026

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia,hon'ble Mr. Justice Bipin Chander NegiView PDF

  8. 08-Dec-2025

    Hon'ble Mr. Justice Ajay Mohan Goel,hon'ble Mr. Justice Jiya Lal BhardwajView PDF

  9. 22-Nov-2025

    Hon'ble Mr. Justice Ajay Mohan Goel,hon'ble Mr. Justice Jiya Lal BhardwajView PDF

  10. 22-Nov-2025

    Admission After Notice

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Jiya Lal Bhardwaj

  11. 14-Oct-2025

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia,hon'ble Mr. Justice Jiya Lal BhardwajView PDF

  12. 14-Oct-2025

    Admission After Notice

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia , Hon'ble Mr. Justice Ranjan Sharma

  13. 08-Sep-2025

    Hon'ble The Chief Justice Gurmeet Singh Sandhawalia,hon'ble Mr. Justice Ranjan SharmaView PDF

  14. 08-Sep-2025

    First hearing

    Initial hearing scheduled

  15. 05-Sep-2025

    Case filed

    Registration No. CWPIL/86/2025

casestatus.in Summary

Summary: CWPIL No. 86/2025 The court adjourned the case regarding a Rs. 469-crore highway 4-laning project (Majrihatta to Nalagarh Chowk). The court expressed concern over NHAI's administrative lapses causing 3-year delays in land acquisition, leading contractor Patel Infrastructure Limited to withdraw via settlement agreement on 09.10.2025. NHAI was directed to file comprehensive affidavits detailing payment amounts, foreclosure justification, and maintenance contract progress. Matter listed for 30.06.2026. This case analysis is maintained by casestatus.in based on publicly available court records.

Explore other courts

District Courts Supreme Court
Search Another Case